[Public Notices] See below two notices from the Lakewood Board of Education:
LAKEWOOD BOARD OF EDUCATION REQUEST FOR PROPOSALS
The LAKEWOOD Board of Education of LAKEWOOD, New Jersey, solicits proposals through the
Invitation for Bids Process
Proposal No BID 29-1920 Title of Proposal: NONPUBLIC SCHOOLS SECURITY SUPPLIES & INSTALLATION
All necessary proposal specifications and proposal forms may be secured upon written request to:
Mr. Kevin Campbell
Assistant Business Administrator
LAKEWOOD Board of Education
200 RAMSEY AVE
LAKEWOOD, New Jersey 08701
FAX: 732-905-3687
E mail: [email protected]
Proposals must be sealed and delivered to the Office of the School Business Administrator/ Board Secretary of LAKEWOOD Board of Education, on or before date and time indicated below. The envelope is to bear the following information:
Title: NONPUBLIC SCHOOLS SECURITY SUPPLIES & INSTALLATION
Proposal No.: BID 29-1920
Name and Address of the Respondent
Date: Wednesday, March 11, 2020
Time: 11:00 A.M.
Location of Proposal Opening
LAKEWOOD BOARD OF EDUCATION
200 Ramsey Ave.
LAKEWOOD, New Jersey 08701
The proposal opening process will begin on the above date and time at the LAKEWOOD Board of Education, LAKEWOOD, New Jersey. Proposals may also be submitted to the School Business Administrator/Board Secretary or his designee at the proposal opening meeting, in the Board Meeting Room, prior to the advertised date and time. On the advertised date and time, the School Business Administrator/Board Secretary shall publicly receive and open all proposals. No proposals shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)).
The Board of Education does not accept electronic (e-mail) submission of Bid proposals.
All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., Affirmative Action Against Discrimination and N.J.A.C. 17:27 et seq.
Each proposal shall be accompanied by a bid bond, cashier’s check or certified check,(when required) made payable to the LAKEWOOD Board of Education, for ten percent (10%) of the amount of the total contract, but not in excess of twenty thousand dollars ($20,000.00).
Corporate respondents are required by law (N.J.S.A. 52:25-24.2) to submit a list of names and addresses of all stockholders owning 10% or more of their stock.
A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the proposal. Failure to complete and submit all required forms may be cause for disqualification and rejection of the proposal.
The Board of Education reserves the right to reject any or all proposals pursuant to N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a), 18A:18A-22, and to waive any informalities.
Mr. Kevin Campbell
Assistant Business Administrator
—————————————————————–
Public Notice 2:
LAKEWOOD BOARD OF EDUCATION REQUEST FOR PROPOSALS
The LAKEWOOD Board of Education of LAKEWOOD, New Jersey, solicits proposals through the
Invitation for Bids Process
Proposal No BID 30-1920 Title of Proposal: NONPUBLIC SCHOOLS WINDOWS & DOORS
All necessary proposal specifications and proposal forms may be secured upon written request to:
Mr. Kevin Campbell
Assistant Business Administrator
LAKEWOOD Board of Education
200 RAMSEY AVE
LAKEWOOD, New Jersey 08701
FAX: 732-905-3687
E mail: [email protected]
Proposals must be sealed and delivered to the Office of the School Business Administrator/ Board Secretary of LAKEWOOD Board of Education, on or before date and time indicated below. The envelope is to bear the following information:
Title: NONPUBLIC SCHOOLS WINDOWS & DOORS
Proposal No.: BID 30-1920
Name and Address of the Respondent
Date: Wednesday, March 11, 2020
Time: 10:00 A.M.
Location of Proposal Opening
LAKEWOOD BOARD OF EDUCATION
200 Ramsey Ave.
LAKEWOOD, New Jersey 08701
The proposal opening process will begin on the above date and time at the LAKEWOOD Board of Education, LAKEWOOD, New Jersey. Proposals may also be submitted to the School Business Administrator/Board Secretary or his designee at the proposal opening meeting, in the Board Meeting Room, prior to the advertised date and time. On the advertised date and time, the School Business Administrator/Board Secretary shall publicly receive and open all proposals. No proposals shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)).
The Board of Education does not accept electronic (e-mail) submission of Bid proposals.
All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., Affirmative Action Against Discrimination and N.J.A.C. 17:27 et seq.
Each proposal shall be accompanied by a bid bond, cashier’s check or certified check,(when required) made payable to the LAKEWOOD Board of Education, for ten percent (10%) of the amount of the total contract, but not in excess of twenty thousand dollars ($20,000.00).
Corporate respondents are required by law (N.J.S.A. 52:25-24.2) to submit a list of names and addresses of all stockholders owning 10% or more of their stock.
A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the proposal. Failure to complete and submit all required forms may be cause for disqualification and rejection of the proposal.
The Board of Education reserves the right to reject any or all proposals pursuant to N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a), 18A:18A-22, and to waive any informalities.
Mr. Kevin Campbell
Assistant Business Administrator