Notice from the Lakewood Board of Education

[Public Notice] The LAKEWOOD Board of Education of LAKEWOOD, New Jersey, solicits proposals through the Invitation for Bids Process

Proposal No BID 25-1920 Title of Proposal: NONPUBLIC SCHOOLS SECURITY SUPPLIES & INSTALLATION

All necessary proposal specifications and proposal forms may be secured upon written request to:

Mr. Robert Finger

Interim Business Administrator

LAKEWOOD Board of Education

200 RAMSEY AVE

LAKEWOOD, New Jersey 08701

FAX: 732-905-3687

E mail: [email protected]

Proposals must be sealed and delivered to the Office of the School Business Administrator/ Board Secretary of LAKEWOOD Board of Education, on or before date and time indicated below. The envelope is to bear the following information:

Title: NONPUBLIC SCHOOLS SECURITY SUPPLIES & INSTALLATION

Proposal No.: BID 25-1920

Name and Address of the Respondent

Date: Tuesday, December 17, 2019

Time: 11:00 A.M.

Location of Proposal Opening

LAKEWOOD BOARD OF EDUCATION

200 Ramsey Ave.

LAKEWOOD, New Jersey 08701

The proposal opening process will begin on the above date and time at the LAKEWOOD Board of Education, LAKEWOOD, New Jersey. Proposals may also be submitted to the School Business Administrator/Board Secretary or his designee at the proposal opening meeting, in the Board Meeting Room, prior to the advertised date and time. On the advertised date and time, the School Business Administrator/Board Secretary shall publicly receive and open all proposals. No proposals shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)).

The Board of Education does not accept electronic (e-mail) submission of Bid proposals.

All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., Affirmative Action Against Discrimination and N.J.A.C. 17:27 et seq.

Each proposal shall be accompanied by a bid bond, cashier’s check or certified check,(when required) made payable to the LAKEWOOD Board of Education, for ten percent (10%) of the amount of the total contract, but not in excess of twenty thousand dollars ($20,000.00).

Corporate respondents are required by law (N.J.S.A. 52:25-24.2) to submit a list of names and addresses of all stockholders owning 10% or more of their stock.

A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the proposal. Failure to complete and submit all required forms may be cause for disqualification and rejection of the proposal.

The Board of Education reserves the right to reject any or all proposals pursuant to N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a), 18A:18A-22, and to waive any informalities.

Mr. Robert Finger

Interim Business Administrator

This content, and any other content on TLS, may not be republished or reproduced without prior permission from TLS. Copying or reproducing our content is both against the law and against Halacha. To inquire about using our content, including videos or photos, email us at [email protected].

Stay up to date with our news alerts by following us on Twitter, Instagram and Facebook.

**Click here to join over 20,000 receiving our Whatsapp Status updates!**

**Click here to join the official TLS WhatsApp Community!**

Got a news tip? Email us at [email protected], Text 415-857-2667, or WhatsApp 609-661-8668.