[Public Notices] See below multiple notices from the Lakewood Board of Education.
LAKEWOOD BOARD OF EDUCATION
REQUEST FOR BIDS
PUBLIC WORKS
Bid Advertisement
The Lakewood Board of Education of Lakewood, New Jersey, hereby advertises for competitive bids in accordance with N.J.S.A. 18A:18A-21(a) (b)
Bid No. 13-1718 Non-Public Schools Window and Door Replacements
Bidders shall be prequalified by the New Jersey Division of Property Management and Construction in the trade categories listed below:
Trade Category # Title
C011 Doors & Hardware
C012 Windows
All necessary bid specifications and bid forms may be secured upon written request to:
Diane Piasentini, QPA
Purchasing Manager
Lakewood Board of Education
200 Ramsey Ave
Lakewood, New Jersey 08701
Fax: 732-905-3574
Email: dpiasentini@Lakewoodpiners.org
Bids must be sealed and delivered to the Office of the School Business Administrator/Board Secretary of the Lakewood Board of Education on or before date and time indicated below. The envelope to bear the following information:
Title: Non-Public Schools Door Replacement
Bid No.: 13-1718
Name and Address of the Bidder
Date: Friday, June 29, 2018
Time: 10:00 a.m.
The bid opening process will begin on the above advertised date and time at the Board Offices 200 Ramsey Ave. Lakewood, New Jersey 08701. Bids may also be submitted to the Interim School Business Administrator/Board Secretary or his designee at the bid opening meeting, prior to the advertised date and time. On the advertised date and time, the Qualified Purchasing Agent shall publicly receive and open all bids. No bids shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)). The Board of Education does not accept electronic (e-mail) submission of bids but requires the submission of a USB Flash drive or CD of your proposal with your paper submission.
All bidders are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., Affirmative Action Against Discrimination (N.J.A.C. 17:27-1 et seq.) An Initial Project Workforce Report will be required from the successful contractor. (Form AA-201).
Contractors bidding on this project are to comply with the requirements of the Prevailing Wage Rate Determination pursuant to N.J.S.A. 34:11-56.25.
A bidder on a public works project for a Board of Education where the cost of the work exceeds $20,000.00 must first have been qualified by the Department of the Treasury, Division of Property Management and Construction, pursuant to N.J.S.A. 18A:18A-27 through 33, and shall submit with his bid a Prequalification Affidavit, a copy of a valid and active NOTICE OF CLASSIFICATION, a certified copy of a Total Amount of Uncompleted Contracts Form and an Affidavit that subsequent to the latest such statement submitted by him, there has been no material adverse change in his qualification information except as set forth in said Affidavit.
Each bid shall be accompanied by a bid bond, cashier’s check or certified check made payable to the Lakewood Board of Education, for ten percent (10%) of the amount of the total bid, however, not to exceed $20,000.00.
Corporate bidders are required by law (Chapter 33, Laws of 1977) to submit a list of names and addresses of all stockholders owning 10% or more of their stock.
The bid package will also include other documents that must be completed and returned with the bid. Failure to comply with Instructions to Bidders and to complete and submit all required forms may be cause for disqualification and rejection of the bid.
All contractors named in this proposal, shall possess a valid Contractor’s Registration Certificate pursuant to N.J.S.A. 34:11-56.48 et seq., at the time the proposal is received by the Board of Education.
The Lakewood Board of Education reserves the right to reject any or all bids, pursuant to N.J.S.A. 18A:18A-18, N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a-c), and N.J.S.A. 18A:18A-22, and to waive any informalities that may be in the best interest of the board.
Kevin Campbell
Interim School Business Administrator/Board Secretary
—————————-
LAKEWOOD BOARD OF EDUCATION
REQUEST FOR BIDS
PUBLIC WORKS
Bid Advertisement
The Lakewood Board of Education of Lakewood, New Jersey, hereby advertises for competitive bids in accordance with N.J.S.A. 18A:18A-21(a) (b)
Bid No. 17-1718 Non-Public School Security Equipment & Installation
Bidders shall be prequalified by the New Jersey Division of Property Management and Construction in the trade categories listed below:
Trade Category # Title
C050 Security/Intrusion Alarms
OR
C047 Electrical
All necessary bid specifications and bid forms may be secured upon written request to:
Diane Piasentini, QPA
Purchasing Manager
Lakewood Board of Education
200 Ramsey Ave
Lakewood, New Jersey 08701
Fax: 732-905-3574
Email: dpiasentini@Lakewoodpiners.org
Bids must be sealed and delivered to the Office of the School Business Administrator/Board Secretary of the Lakewood Board of Education on or before date and time indicated below. The envelope to bear the following information:
Title: Non-Public Schools Security Equipment & Installation
Bid No.: 17-1718
Name and Address of the Bidder
Date: Tuesday, June 26, 2018
Time: 12:00 NOON
The bid opening process will begin on the above advertised date and time at the Board Offices 200 Ramsey Ave. Lakewood, New Jersey 08701. Bids may also be submitted to the Interim School Business Administrator/Board Secretary or his designee at the bid opening meeting, prior to the advertised date and time. On the advertised date and time, the Qualified Purchasing Agent shall publicly receive and open all bids. No bids shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)). The Board of Education does not accept electronic (e-mail) submission of bids.
All bidders are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., Affirmative Action Against Discrimination (N.J.A.C. 17:27-1 et seq.) An Initial Project Workforce Report will be required from the successful contractor. (Form AA-201).
Contractors bidding on this project are to comply with the requirements of the Prevailing Wage Rate Determination pursuant to N.J.S.A. 34:11-56.25.
A bidder on a public works project for a Board of Education where the cost of the work exceeds $20,000.00 must first have been qualified by the Department of the Treasury, Division of Property Management and Construction, pursuant to N.J.S.A. 18A:18A-27 through 33, and shall submit with his bid a Prequalification Affidavit, a copy of a valid and active NOTICE OF CLASSIFICATION, a certified copy of a Total Amount of Uncompleted Contracts Form and an Affidavit that subsequent to the latest such statement submitted by him, there has been no material adverse change in his qualification information except as set forth in said Affidavit.
Each bid shall be accompanied by a bid bond, cashier’s check or certified check made payable to the Lakewood Board of Education, for ten percent (10%) of the amount of the total bid, however, not to exceed $20,000.00.
Corporate bidders are required by law (Chapter 33, Laws of 1977) to submit a list of names and addresses of all stockholders owning 10% or more of their stock.
The bid package will also include other documents that must be completed and returned with the bid. Failure to comply with Instructions to Bidders and to complete and submit all required forms may be cause for disqualification and rejection of the bid.
All contractors named in this proposal, shall possess a valid Contractor’s Registration Certificate pursuant to N.J.S.A. 34:11-56.48 et seq., at the time the proposal is received by the Board of Education.
The Lakewood Board of Education reserves the right to reject any or all bids, pursuant to N.J.S.A. 18A:18A-18, N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a-c), and N.J.S.A. 18A:18A-22, and to waive any informalities that may be in the best interest of the board.
Kevin Campbell
Interim School Business Administrator/Board Secretary
——————
LAKEWOOD BOARD OF EDUCATION
REQUEST FOR PROPOSALS
The LAKEWOOD Board of Education of LAKEWOOD, New Jersey, solicits proposals through the
Request for Proposal Process (RFP) for
Proposal No BID 06-1819 Title of Proposal: AFTER SCHOOL PROGRAM GRADES K-5
All necessary proposal specifications and proposal forms may be secured upon written request to:
Mr. Kevin Campbell
Interim School Business Administrator/Board Secretary
LAKEWOOD Board of Education
200 RAMSEY AVE
LAKEWOOD, New Jersey 08701
FAX: 732-905-3687
E mail: dpiasentini@lakewoodpiners.org
Proposals must be sealed and delivered to the Office of the School Business Administrator/ Board Secretary of LAKEWOOD Board of Education, on or before date and time indicated below. The envelope is to bear the following information:
Title: AFTER SCHOOL PROGRAM GRADES K-5
Proposal No.: BID 06-1819
Name and Address of the Respondent
Date: Friday, July 6, 2018
Time: 11:00 A.M.
Location of Proposal Opening
LAKEWOOD BOARD OF EDUCATION
200 Ramsey Ave.
LAKEWOOD, New Jersey 08701
The proposal opening process will begin on the above date and time at the LAKEWOOD Board of Education, LAKEWOOD, New Jersey. Proposals may also be submitted to the School Business Administrator/Board Secretary or his designee at the proposal opening meeting, in the Board Meeting Room, prior to the advertised date and time. On the advertised date and time, the School Business Administrator/Board Secretary shall publicly receive and open all proposals. No proposals shall be received after the time designated in the advertisement. (N.J.S.A. 18A:18A-21(b)).
The Board of Education does not accept electronic (e-mail) submission of Competitive Contracting proposals.
All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et seq., Affirmative Action Against Discrimination and N.J.A.C. 17:27 et seq.
Each proposal shall be accompanied by a bid bond, cashier’s check or certified check,(when required) made payable to the LAKEWOOD Board of Education, for ten percent (10%) of the amount of the total contract, but not in excess of twenty thousand dollars ($20,000.00).
Corporate respondents are required by law (N.J.S.A. 52:25-24.2) to submit a list of names and addresses of all stockholders owning 10% or more of their stock.
A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the proposal. Failure to complete and submit all required forms, may be cause for disqualification and rejection of the proposal.
The Board of Education reserves the right to reject any or all proposals pursuant to N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a), 18A:18A-22, and to waive any informalities.
Mr. Kevin Campbell
Interim School Business Administrator
——————-
LAKEWOOD BOARD OF EDUCATION
REQUEST FOR PROPOSALS
RFP Advertisement
The Board of Education of the City of Lakewood, New Jersey, hereby advertises for Request for Proposals (RFP) for the School Year 2018-2019:
SCHOOL PHYSICIAN OF RECORD
RFP No. 10-1819
Term of Contract: July 1, 2018 through June 30, 2019
All necessary proposal specifications and proposal forms may be secured upon written request to:
Mr. Kevin Campbell
Interim School Business Administrator/Board Secretary
Lakewood Board of Education
200 Ramsey Avenue
Lakewood, NJ 08701
Fax: 732-905-3687
E mail: dpiasentini@lakewoodpiners.org
Proposals must be sealed, the envelope to bear the following information:
Title: SCHOOL PHYSICIAN OF RECORD 2018-2019
RFP No. 10-1819
Name and Address of the Respondent
and delivered to the Business Office of the Lakewood Board of Education on or before
Date: Thursday, July 12, 2018
Time: 12:00 noon
All respondents are required to comply with the requirements of N.J.S.A. 10:5-31 et. seq., Affirmative Action Against Discrimination and N.J.A.C. 17:27 et seq.
A Non-Collusion Affidavit and a Contractor Questionnaire/Certification also must be filed with the proposal. The proposal package will also include other documents that must be completed and returned with the RFP package. Failure to complete and submit all required forms may be cause for disqualification and rejection of the proposal.
The Board of Education reserves the right to reject any or all proposals pursuant to N.J.S.A. 18A:18A-2(s), (t), (x), (y), 18A:18A-4(a), 18A:18A-22, and to waive any informalities. The Board further reserves the right to take such alternates as they deem appropriate, and in any order that the Board feels may be in the best interest of the Lakewood Board of Education.
Mr. Kevin Campbell
Interim School Business Administrator/Board Secretary